Definitions

As used in this article, the term: 1411 36-91-101 (1) ‘‘Affected local government’’ means any county, municipality, or consolidated government in which water storage facilities of a project are located or proposed to be located, which will receive for local use water or services from such project, or which, under a service delivery agreement entered into pursuant to Article 2 of Chapter 70 of this title, provides or is authorized to provide within an area water facilities or services similar to water facilities and services proposed to be provided by a project in such area. (2) ‘‘Lead local authority’’ means the sole local governing authority or local authority participating in a project or the local governing authority or local authority designated pursuant to subsection (b) of Code Section 36-91-102. (3) ‘‘Local authority’’ means any local water authority created by Act of the General Assembly, any authority created pursuant to the provisions of Chapter 62 of this title, and any authority created by a county, municipality, or consolidated government which provides water, sewer, or waste-water treatment services. (4) ‘‘Local governing authority’’ means any county, municipality, or consolidated government. (5) ‘‘Project’’ has the meaning provided by paragraph (10) of Code Section 12-5-471 and includes environmental facilities as defined in subparagraph (B) of paragraph (5) of Code Section 50-23-4. History. — Code 1981, § 36-91-100, enacted by Ga. L. 2011, p. 52, § 1/SB 122; Ga. L. 2012, p. 775, § 36/HB 942. 36-91-101. Authority to enter into contracts; costs; grants or loans; eminent domain. (a) Local governing authorities and local authorities shall be authorized to enter into contracts provided for by this article with private persons, firms, associations, or corporations providing for or delegating the responsibility for procuring all permits, licenses, and permissions from the United States of America or any agency or instrumentality thereof; the State of Georgia, its departments, agencies, or authorities; or any county or municipality of this state as necessary or required for the purpose of constructing projects within this state, and to plan, finance, construct, acquire, lease, operate, or maintain such projects or cause such projects to be planned, financed, constructed, acquired, leased, operated, or maintained. Such contracts may provide for the reimbursement to the private person, firm, association, or corporation of costs and expenses associated with the execution thereof through service payments, user fees, purchase payments, and such other consideration as the local governing authority or local authority may 1412 36-91-102 deem appropriate. Such contracts may provide for the assumption by such local governing authority or local authority of such projects, permits, licenses, and permissions at such times as appropriate for the construction of the project or as otherwise agreed upon. (b) A local governing authority or local authority may take any action to obtain federal, state, or local assistance for a project that serves the public purpose of this article and may enter into any contracts required to receive such assistance. A local governing authority or local authority may determine that it serves the public purpose of this article for all or any portion of the costs of a project to be paid, directly or indirectly, from the proceeds of a grant or loan made by the federal, state, or local government or any instrumentality thereof. A local governing authority or local authority may agree to make grants or loans to the operator of a project from time to time from amounts received from the federal, state, or local government or any agency or instrumentality thereof. (c) Nothing in this article shall be construed to delegate the power of eminent domain to any private entity with respect to any project commenced or proposed pursuant to this article. Any local governing authority may exercise the power of eminent domain in the manner provided by law for the purpose of acquiring any property or interests therein to the extent that such action serves the public purpose of this article. History. — Code 1981, § 36-91-101, enacted by Ga. L. 2011, p. 52, § 1/SB 122. 36-91-102. Planning, finance, construction, acquisition, leasing, operation, and maintenance of projects; implementation; lobbying restrictions. (a) In addition to other methods of procurement authorized by law, local governing authorities and local authorities shall be authorized to utilize the procedures of this article to provide for the planning, finance, construction, acquisition, leasing, operation, and maintenance of projects. The provisions of this article shall be an alternative to such other methods to be exercised at the option of each local governing authority or local authority. (b) After identifying or being informed of any project that may be suitable for utilization of the procedures of this article, one or more local governing authorities and local authorities may participate in consideration and implementation of a project. Where more than one local governing authority or local authority agrees to participate in consideration or implementation of a project, the participants shall designate one of their number to be the lead local authority for purposes of implementing the procedures of this article; provided, however, that not 1413 36-91-102 less than one representative of each such participating local governing authority or local authority, as agreed to by such local governing authorities or local authorities, shall have the right to participate in all aspects of such implementation. (c)(1) The lead local authority shall evaluate a project to determine, in the judgment of the lead local authority, appropriate or desirable levels of state, local, and private participation in financing, constructing, and operating such project. In making such determinations, the lead local authority shall seek the advice and input of affected local governments and is encouraged to seek the advice and input of the Water Supply Division of the Georgia Environmental Finance Authority, affected local governing authorities, applicable planning organizations, and the private financial and construction sectors. (2) The lead local authority shall be authorized to issue a written request for proposals indicating the scope of the project, the proposed financial participations in the project, and the factors that will be used in evaluating the proposals as well as the relative importance of the evaluation factors, and containing or incorporating by reference other applicable contractual terms and conditions, including any unique capabilities or qualifications that will be required of the contractor. Public notice of such request for proposal shall be made at least 90 days prior to the date set for receipt of proposals by posting the legal notice on the websites of each participating local governing authority and local authority in substantially the same manner utilized by such authority to solicit requests for proposals, with a copy of such notice provided simultaneously to each affected local government. (3) Upon receipt of a proposal or proposals responsive to the request for proposals, the lead local authority shall accept written public comment, solicited in the same manner as provided for notice of proposals, for a period of 30 days beginning at least ten days after the date set for receipt of proposals. In addition, the lead local authority shall hold at least one public hearing on such proposals within the jurisdiction of each participating local governing authority, participating local authority, or affected local government not later than the conclusion of the period for public comment. (4)(A) The lead local authority, acting by and through a designated representative appointed for such purposes, and with the participation of any designated representatives of other participating local governing authorities or local authorities, shall engage in individual discussions with each respondent deemed fully qualified, responsible, and suitable on the basis of initial responses and with emphasis on professional competence and ability to meet the level of private financial participation called for by the local 1414 36-91-102 governing authority. Repetitive informal interviews shall be permissible. Any affected local governments shall receive ten days’ notice of any such individual discussions and interviews and may participate through an appointed representative. In the event that the Georgia Environmental Finance Authority or any other state authority or agency agrees to consider or participate in the project, a representative of such authority or agency appointed by such authority or agency may participate in such discussions and interviews. (B) At the discussion stage, the representatives may discuss estimates of total project costs, including, but not limited to, life cycle costing and nonbinding estimates of price for services. Discussions conducted with respondents pursuant to this subparagraph shall not be public meetings subject to the provisions of Chapter 14 of Title 50. Proprietary information or trade secrets may be designated by a respondent as subject to one or more exemptions from public disclosure pursuant to the provisions of Code Section 50-18-72, but such designation shall not be binding on the participating local governing authorities, local authorities, and affected local governments unless consistent with applicable law. (C)(i) At the conclusion of the discussion stage, on the basis of evaluation factors published in the request for proposal and all information developed in the selection process, the designated representative, with the input of the representatives of any other participating entity and in an open and public meeting subject to the provisions of Chapter 14 of Title 50, shall select in the order of preference one or more respondents whose qualifications and proposed services are deemed most meritorious. (ii) Negotiations shall then be conducted by the designated representative with the selected respondents. A representative of any participating local governing authority, participating local authority, and participating state agency or authority shall have the right to notice of and participation in such negotiations. Negotiations conducted with selected respondents pursuant to this division shall not be public meetings subject to the provisions of Chapter 14 of Title 50. (D) The designated representative shall select for approval by the lead local authority the respondent for project implementation based upon contract terms that are the most satisfactory and advantageous to the participating local governing authorities and local authorities based upon a thorough assessment of value and the ability of the final project’s characteristics to meet the goals of the participating local governing authorities and local authorities, consistent with applicable state-wide and regional water plans and 1415 36-91-102 local comprehensive plans. Before making such selection, the designated representative shall consult in an open and public meeting subject to the provisions of Chapter 14 of Title 50 with the representatives of any participating local governing authority, participating local authority, participating state agency or authority, and affected local government. Notwithstanding the foregoing, if the terms and conditions for multiple awards are included in the request for proposal, the lead local authority may award contracts to more than one respondent. Should the lead local authority determine in writing that only one respondent is fully qualified, or that one respondent is clearly more highly qualified and suitable than the others under consideration, a contract may be negotiated and awarded to that respondent. (E) Upon approval of the selection by the lead local authority, a contract or contracts not exceeding 50 years in duration may be entered into with the selected respondents on behalf of all participating entities, subject to approval by each such participating entity and by each affected local government. (5) A dispute over the award of a contract under this article shall be resolved by the filing of a petition in the superior court of the county in which the lead local authority is located within 30 days of the awarding of such contract and shall be determined through the use of a special master appointed by the judge of the superior court of the county in which the lead local authority is located. The decision of the special master with regard to such dispute shall be appealable for a de novo review to the superior court of the county in which the lead local authority is located within 30 days following the decision of the special master. Neither the special master nor the superior court shall be authorized to enjoin or otherwise delay or suspend the execution of the contract and any work to be performed under such contract. (6) Nothing in this Code section shall require the designated representatives, the lead local authority, or any local governing authority, local authority, or state agency or authority to continue negotiations or discussions arising out of any request for proposal. (7) Every local governing authority and local authority shall be authorized to promulgate reasonable rules or regulations to assist in its evaluation of proposals and to implement the purposes of this article. (d) No public officer, employee, or member of a local governing authority or local authority, with respect to contracts of such local governing authority or local authority, or the General Assembly shall serve as an agent, lobbyist, or board member for any private entity 1416 36-91-110 directly or indirectly under a contract or negotiating a contract provided for by this article for three years after leaving his or her position as a public officer, employee, or member of the local governing authority, local authority, or the General Assembly. History. — Code 1981, § 36-91-102, enacted by Ga. L. 2011, p. 52, § 1/SB 122; Ga. L. 2012, p. 775, § 36/HB 942. ARTICLE 5 PARTNERSHIP FOR PUBLIC FACILITIES AND INFRASTRUCTURE Editor’s notes. — Ga. L. 2015, p. 406, § 1/SB 59, not codified by the General Assembly, provides: ‘‘This Act shall be known and may be cited as the ‘Partnership for Public Facilities and Infrastructure Act.’ ’’ 36-91-110. Definitions.