Chapter 254

Section 13. The rights of an attaching creditor shall not prevail as against a lien under section 1, nor against the claim of a lienor if notice or notices of contract have been filed or recorded in the registry of deeds under sections 2, 2C, 2D or 4 prior to the recording of the…

Section 14. Any person in interest may dissolve a lien under this chapter by recording or causing to be recorded in the registry of deeds in the county or district where the land lies, a bond of a surety company authorized to do business in Massachusetts and in a penal sum equal …

Section 15. If it appears to the court that no person is entitled to a lien, or that every lien has been discharged by payment thereof, judgment shall be entered to the effect that the lien is dissolved, and a certificate to that effect shall be sent forthwith by the clerk to the…

Section 15A. If any person in interest, including but not limited to an owner, contractor, or mortgage holder, claims (a) that any person who has provided labor or materials or has agreed to provide funding, financing or payment for labor or materials, refuses to continue to prov…

Section 17. A claim due absolutely and without condition, although not payable at the time of determination, shall be allowed with a rebate of interest to the time when it would become payable. If the owner has failed to perform his part of the contract and by reason of such fail…

Section 18. If a lien is established the court shall order a sale of the property to be made by an officer qualified to serve civil process. The court may order a sale of a part of the property sufficient to satisfy the claims allowed, if such part can be set off from the residue…

Section 19. The officer shall give notice of the time and place of sale as provided for sales of land on execution or as ordered by the court.

Section 2. A person entering into a written contract with the owner of any interest in real property, or with any person acting for, on behalf of, or with the consent of such owner for the whole or part of the erection, alteration, repair or removal of a building, structure, or o…

Section 20. An interest in land sold under this chapter may be redeemed within ninety days after such sale in the manner provided for sales of land on execution.

Section 21. If all the claims against the property covered by the lien were ascertained at the time of ordering the sale and if the proceeds of the sale are sufficient therefor, the court may order the officer to distribute them, after deducting all lawful charges and expenses of…

Section 22. Costs shall be in the discretion of the court and shall be paid from the proceeds of the sale or by any of the parties, as it may order.

Section 23. If the person for whom the labor or material has been furnished or professional services have been performed dies or conveys away his estate or interest before the commencement of a civil action to enforce a lien, it may be commenced and prosecuted against his heirs o…

Section 24. If the creditor dies without having commenced such action, it may be commenced and prosecuted by his executor or administrator, or if he dies after having commenced it, it may be so prosecuted.

Section 25. If the person for whom the labor has been performed or with whom the original contract has been entered into for the whole or any part of the erection, alteration, repair or removal of a building or structure upon land, or for furnishing material or performing profess…

Section 26. This chapter shall not prevent a person entitled to a lien under it from maintaining a civil action as if he had no lien.

Section 27. A person entering into a written contract with the owner of land or flats for reclaiming or raising the level thereof by suction, hydraulic or any other form of dredging, or for furnishing material therefor, or the trustee or trustees of any fund or funds, described i…

Section 28. Whoever, subsequent to the date of the original contract, furnishes labor or material, or both labor and material, under a written contract with a contractor contracting as provided in section twenty-seven, or with a sub-contractor of such contractor, may file in the …

Section 29. All the provisions of this chapter relative to liens for the erection, alteration, repair or removal of a building or structure or for furnishing material therefor, attaching under the provisions of section two or four, shall apply, so far as apt, to liens attaching u…

Section 2A. As used in this chapter the following words shall, unless the context clearly requires otherwise, have the following meaning:— ''Design professional'', an architect, landscape architect, professional engineer, licensed site professional or land surveyor who is license…

Section 2B. If, prior to the filing or recording in the registry of deeds and delivery of the copies of the notice of substantial completion described in section two A, any contract subject to the provisions of section two shall have been terminated, the owner shall execute and f…

Section 2C. A design professional entering into a written contract with the owner of any interest in real property or with any person acting for, on behalf of, or with the consent of such owner, for the provision of professional services relating to the proposed or actual erectio…

Section 2D. Any person who furnishes professional services under a written subcontract with a design professional who is entitled to enforce a lien under section 2C and whose engagement has been approved in writing by or on behalf of the owner of the interest in land to which lie…

Section 30. All liens for labor and notices of contract, and instruments pertaining thereto, filed as provided for in this chapter, shall be recorded by the register of deeds, who shall enter the names of the parties affected thereby in the grantor and grantee indexes. Any notice…

Section 31. In the event that a general contractor or a subcontractor on any construction work is adjudged a bankrupt, or makes a general assignment for the benefit of creditors, or if a receiver is appointed on account of the insolvency of the general contractor or of a subcontr…

Section 32. A covenant, promise, agreement of understanding in, or in connection with or collateral to, a contract or agreement relative to the construction, alteration, repair or maintenance of a building, structure, appurtenance and appliance or other improvement to real proper…

Section 33. Except with respect to any construction project containing or designed to contain at least one but not more than four dwelling units, the filing or recording of documents claiming a lien under section two, or the filing or recording of a statement pursuant to section …

Section 4. Whoever furnishes labor, including subcontractor construction management services, or who furnishes material, or both labor and material, or furnishes rental equipment, appliances or tools, or who performs professional services, under a written contract with a contract…

Section 5. A lien upon land for the erection, alteration, repair or removal of a building or other structure or other improvement of real property or for professional services relating thereto or a lien established under section seventy-six of chapter sixty-three, or section 6 of…

Section 5A. When the amount of a lien under section six of chapter 183A or under section 29 of chapter 183B has been established by a court, the court shall enter an order authorizing the sale of the real estate to satisfy such lien. The lienor may do all acts authorized by such …

Section 6. No lien shall attach to any land, building or structure thereon owned by the commonwealth, or by a county, city, town, water or fire district.

Section 7. (a) No lien under section one shall avail against a mortgage duly registered or recorded unless the work or labor performed is in the erection, alteration, repair or removal of a building, structure, or other improvement to real property which erection, alteration, rep…

Section 8. Liens under sections two and four shall be dissolved unless the contractor, subcontractor, or some person claiming by, through or under them, shall, not later than the earliest of: (i) ninety days after the filing or recording of the notice of substantial completion un…

Section 9. Any notice or any statement provided for in this chapter shall remain in the custody of the register and be open to public inspection. He shall record it in a book kept therefor, but the items of the account, except the total amount claimed due, may be omitted from the…