Title 29, Mortgages and Other Liens

(1) When a governmental body is a party to a contract to improve real property, and the contract is for a sum in excess of fifty thousand dollars, the owner of the property shall require the contractor to provide a labor and material payment bond in the full amount of the contrac…

For any contract for the improvement of real property not covered by the provisions of Section 29-6-250, where a payment bond is required by the contract or otherwise, the bond may only be issued by a surety company licensed in the State with a "B+" minimum rating as stated in th…

A provision in a contract for the improvement of real property in the State must not operate to derogate the rights of a construction contractor, subcontractor, supplier, or other proper claimant against a payment bond or other form of payment security or protection established b…

When a contractor or a subcontractor has performed in accordance with the provisions of his contract, the owner shall pay the contractor by mailing via first class mail or delivering the undisputed amount of any pay request within twenty-one days of receipt by the owner of any pa…

Nothing in this chapter prevents the owner, the contractor, or a subcontractor from withholding application and certification for payment because of the following: unsatisfactory job progress, defective construction not remedied, disputed work, third party claims filed or reasona…

If a periodic or final payment to a contractor is delayed by more than twenty-one days or if a periodic or final payment to a subcontractor is delayed by more than seven days after receipt of periodic or final payment by the contractor or subcontractor, the owner, contractor, or …

The provisions of this chapter do not apply to: (1) residential homebuilders; (2) improvements to real property intended for residential purposes which consist of sixteen or fewer residential units; or (3) private persons or entities owning improvements to real property when the …